Effective Date: April 22, 2025
By accessing or using the website (amazingfacade.info), engaging with our team, or availing our services, you agree to be bound by the following terms and conditions (“Terms”). Please read them carefully before proceeding.
1. General Use
- This website is owned and operated by Amazing Facade Pvt. Ltd., a registered company under the Companies Act, India.
- These Terms govern your use of our website, content, and communication channels.
- By using our site or services, you confirm that you are at least 18 years old and legally permitted to enter into contracts.
2. Intellectual Property
- All content on this website — including text, images, graphics, designs, trademarks, and logos — is the intellectual property of Amazing Facade Pvt. Ltd. or its partners.
- You may not reproduce, reuse, distribute, or modify any part of this website without our explicit written permission.
3. Services & Engagement
- All service proposals, quotations, or project timelines are subject to mutual agreement and written confirmation.
- Project scope, deliverables, and payment terms will be defined in the proposal or work order specific to each client.
- Changes to the scope or delays caused by third parties may affect delivery schedules and pricing.
4. Pricing & Payment
- All quotations provided are exclusive of applicable taxes unless otherwise mentioned.
- A minimum advance (as per agreement) is required to initiate any project.
- Payment delays beyond the due date may incur interest and/or pause ongoing work until dues are cleared.
5. Warranty & Liability
- We ensure strict quality control and technical precision in all our products and installations.
- However, Amazing Facade Pvt. Ltd. shall not be liable for:
- Delays caused by force majeure, site inaccessibility, or client-side lapses
- Damages arising from misuse, third-party modifications, or lack of maintenance
- Any warranty terms (if applicable) will be detailed in the project agreement.
6. Client Responsibilities
- Clients must provide accurate project details, drawings, timelines, and site access where necessary.
- Any delays in providing inputs or approvals may impact the project schedule and costs.
7. Third-Party Tools & Links
- We may use third-party tools (e.g., WhatsApp, Google Drive, CRM systems) to coordinate with clients.
- We are not liable for the performance, data policies, or errors from such third-party platforms.
8. Website Availability
- While we strive to keep our site accessible and accurate, we make no guarantees regarding uninterrupted access, bug-free operation, or real-time updates.
- We reserve the right to update or suspend any part of the website without notice.
9. Privacy
- Our Privacy Policy outlines how we collect, use, and protect user data. By using our site, you agree to our data practices.
10. Governing Law
These Terms shall be governed by and construed in accordance with the laws of India, with exclusive jurisdiction in the courts of Hyderabad, Telangana.
📞 Contact Us
For any questions regarding these Terms, please contact:
Amazing Facade Pvt. Ltd.
📧 amazingfacade2016@gmail.com
📞 +91 9951928758 | +91 9010375881
📍 Hyderabad, India